NOTICE TO RECEIVE SEALED BIDS
The City of Mexico Beach will receive sealed bids from any qualified person, company or corporation interested in constructing:
MEXICO BEACH SANITARY SEWER MITIGATION REPAIRS
The City of Mexico Beach is soliciting for a product or process to prevent floodwater from entering the sanitary system through the manholes covers. Bid to include the product and implementation on all sanitary manholes in the City of Mexico Beach.
Contact Doug Baber at firstname.lastname@example.org for required bid documents.
The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
The completion date for this project will be 90 days for Substantial Completion and 100 days for Final Completion from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $100.00 per day.
Please indicate on the envelope that this is a sealed bid, for the MEXICO BEACH SANITARY SEWER MITIGATION REPAIRS
The City of Mexico Beach reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in their best interest. All bids shall remain firm for a period of ninety (90) days after the opening.
Questions regarding the project must be submitted in writing to Doug Baber at email@example.com prior by 2:00 p.m. Central Time Wednesday, February 2, 2022.
Bids will be received until 2:00 p.m. Central Time, on Thursday, February 17, 2022 at Mexico Beach City Hall -City Clerk, 201 Paradise Path, Mexico Beach, Florida 32456, and will be opened and read aloud thereafter at 2:05 p.m. Central Time.
All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida. The City of Mexico Beach is an Equal Opportunity Employer.
No comments on this item Please log in to comment by clicking here