maddox park gazebo
NOTICE TO RECEIVE SEALED BIDS
REBID OF RFP 2021-08
The City of Port St. Joe will receive sealed bids from any qualified person, company or corporation interested in constructing the:
MADDOX PARK GAZEBO
The proposed project includes the construction of a 32 ft. diameter wood frame gazebo along with brick paver walkways that connect to the existing Port City Trail.
Bid documents can be obtained by contacting Sharon Harrell at firstname.lastname@example.org with Dewberry Engineers Inc., 324 Marina Drive, Port St. Joe, FL 32456, (850) 227-7200. Cost for Plans and Specifications will be $25.00 per set and is non-refundable. Checks should be made payable to DEWBERRY ENGINEERS INC. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
Completion date for this project will be 60 days for Substantial Completion and 75 days for Final completion from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day.
Please indicate on the envelope that this is a sealed bid for the "MADDOX PARK GAZEBO."
Bids will be received until 3:00 P.M. ET, on December 21, 2021, at the Port St. Joe City Hall, 305 Cecil G. Costin Sr. Boulevard, Port St. Joe, FL 32456, and will be opened and read aloud on December 21, 2021, at 3:05 P.M.
The City of Port St. Joe reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of The City of Port St. Joe. All bids shall remain firm for a period of sixty days after the opening. The City of Port St. Joe is an Equal Opportunity, Affirmative Action, Drug Free Work Place Employer.
Questions regarding the project must be submitted in writing to Josh Baxley at email@example.com prior to 3:00 p.m. Eastern Time on December 14, 2021.
All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida.If you have any questions, please contact Josh Baxley at (850) 693-2181 or email at firstname.lastname@example.org.
Publish Dates: November 18 & 25, 2021
No comments on this item Please log in to comment by clicking here